Introduction 

Welcome to https://newfore.com (the “Website” or “Site”). This Site is operated by Newfore Inc., a company specializing in construction and renovation services, including: 

  1. Residential Projects: Custom home builds, complete home renovations, kitchen/bathroom remodels, basement finishing 
  1. Commercial Renovations: Office renovations, retail space redesigns, restaurant renovations, industrial space upgrades 
  1. Engineering and Permits 
  1. Renovations (both residential and commercial) 
  1. Construction Management 

By accessing or using our Website, requesting a quote, or engaging with us for any of the above services, you (“User” or “Client”) agree to be bound by these Terms & Conditions (the “Terms”). If you do not agree, please discontinue use of our Site. 

Scope of Services 

  1. Informational Website: The Website primarily serves as a platform to provide information about Newfore’s offerings, service areas, and project capabilities. 
  1. No Guarantee of Specific Results: While we endeavor to keep our content accurate and up to date, we do not guarantee that the information on our Site will meet your specific needs or expectations. 
  1. Separate Contracts: If you contract with us for construction or renovation services, a separate written agreement (e.g., proposal, work order, or construction contract) will govern the specific scope of work, payment terms, warranties, and other project details. In the event of conflict, the executed contract shall take precedence over these Terms. 

Acceptance of Terms 

  1. Binding Agreement: By using or accessing our Site, you acknowledge that you have read, understood, and agree to these Terms as well as our Privacy Policy. 
  1. Updates: We reserve the right to modify these Terms at any time. If we make substantial changes, we will notify users by posting the updated Terms on our Site with a new “Effective Date.” Your continued use of the Site after such changes signifies your acceptance of the revised Terms. 

Eligibility 

  1. Age Requirement: You must be at least 18 years old (or the age of majority in your jurisdiction) to use our Site or engage our services. 
  1. Legal Capacity: By using our Site or services, you represent and warrant that you have the legal capacity to enter into these Terms and are not prohibited from doing so under any laws. 

 

Permits, Laws, and Regulations (For Construction Services) 

  1. Regulatory Compliance: Newfore will obtain, or assist the Client in obtaining, any required permits, licenses, or approvals for construction or renovation projects if outlined in the project proposal or contract. 
  1. Client Responsibilities: The Client shall provide accurate information regarding property boundaries, utilities, and site conditions. Newfore is not responsible for project delays or issues arising from inaccurate or incomplete information. 
  1. Applicable Laws: Both parties agree to comply with all federal, state/provincial, and local laws, building codes, and regulations relevant to the project. 

Quality of Work and Materials 

  1. Workmanship: All construction or renovation work performed by Newfore or its authorized subcontractors will be done professionally and in accordance with industry standards. 
  1. Materials: Unless specified otherwise, we will use materials of standard quality suitable for the intended design. Any material substitutions will be communicated to the Client and must be approved in writing. 

Subcontractors and Suppliers 

  1. Authorization: We reserve the right to employ subcontractors or third-party suppliers for specific tasks or specialized work. 
  1. Responsibility: We maintain oversight and responsibility for ensuring that subcontractors meet the quality standards and terms set forth in the project agreement and these Terms. 

Website Use and User Responsibilities 

  1. Lawful Use: You agree to use our Site only for lawful purposes and in compliance with these Terms and any applicable laws or regulations. 
  1. No Harmful Acts: You must not introduce viruses, malware, or any other harmful material to the Site, nor attempt unauthorized access to any part of the Site or its servers. 
  1. Account Security: If you create an account on our Site (e.g., for project management portals or quote requests), you are responsible for maintaining the confidentiality of your login credentials. You must notify us immediately of any unauthorized use of your account. 

Intellectual Property 

  1. Ownership: All content on the Site—including text, images, graphics, software, and trademarks—is owned or licensed by Newfore and is protected by intellectual property laws. 
  1. Limited License: You may view, download, and print content from the Site for personal, non-commercial use. Any other use (e.g., reproduction, modification, distribution) requires our express written consent. 

Third-Party Links 

  1. External Websites: Our Site may contain links to third-party websites for informational purposes. These links do not imply endorsement or approval of the linked sites. 
  1. No Liability: We are not responsible for the content, practices, or policies of any third-party sites and encourage you to read their terms and policies carefully. 

Disclaimers 

  1. As-Is Basis: Our Site and its content are provided on an “as-is” and “as-available” basis. To the fullest extent permitted by law, we disclaim any warranties, express or implied, including warranties of merchantability, fitness for a particular purpose, and non-infringement. 
  1. Construction and Renovation Advice: Any advice or information provided on our Site regarding construction, renovation, or other related services is general in nature. Professional consultation or a formal contract is recommended before making decisions or undertaking any project. 

Limitation of Liability 

  1. Exclusion of Damages: To the maximum extent permitted by law, Newfore and its affiliates, employees, or subcontractors shall not be liable for any indirect, incidental, special, or consequential damages arising out of or connected to your use of the Site or our services. 
  1. Total Liability: In no event shall our total liability for any claim exceed the amount you have paid (if any) for accessing or using our Site or services. 

Indemnification 

Your Obligation: You agree to defend, indemnify, and hold harmless Newfore, its affiliates, and their respective officers, employees, and agents from any and all claims, damages, obligations, losses, liabilities, costs, or debt arising from: 

  1. Your use of the Site or our services, 
  1. Your violation of these Terms, or 
  1. Your violation of any applicable law or rights of a third party. 

Payment Terms (If Engaging Construction Services) 

  1. Project Proposal: Each project will be accompanied by a proposal or estimate detailing costs, timelines, and deliverables. 
  1. Payment Schedule: Payment milestones (e.g., deposit, progress payments, final payment) will be outlined in the project contract. Late payments may incur interest or fees. 
  1. Changes and Change Orders: Any modifications to the original scope, materials, or schedule must be documented in a signed change order, which may affect the total cost and completion date. 

 

 

Default and Termination 

  1. Default by Newfore: If Newfore fails to fulfill a material obligation under these Terms or an executed contract and does not remedy such breach within a reasonable period after written notice, the Client may terminate the agreement. 
  1. Default by Client: If the Client fails to make payments when due or otherwise breaches a material term, and does not cure such breach after notice, Newfore may suspend or terminate services. 
  1. Survival: Upon termination, provisions relating to intellectual property, limitations of liability, and indemnification shall survive. 

Dispute Resolution and Governing Law 

  1. Good Faith Negotiations: In the event of any dispute, both parties agree to make a good-faith effort to resolve it through direct negotiation or mediation before pursuing other remedies. 
  1. Arbitration or Litigation: If negotiation or mediation fails, disputes may be resolved through arbitration or litigation as specified in the project contract or, if not specified, in accordance with the laws of Hamilton, Ontario. 
  1. Governing Law: These Terms shall be governed by the laws of [Your Country/State], without regard to conflict-of-law principles. The courts located in [Your Jurisdiction] shall have exclusive jurisdiction over any disputes. 

Privacy and Data Protection 

  1. Privacy Policy: Our collection and processing of personal information is governed by our Privacy Policy, which forms part of these Terms. 
  1. Data Security: While we take reasonable measures to protect user data, no method of transmission or storage is completely secure. You agree that you provide any personal information at your own risk. 

Force Majeure 

Events Beyond Our Control: Newfore shall not be liable for delays or failure to perform resulting from circumstances beyond our reasonable control, including but not limited to natural disasters, pandemics, strikes, supply chain disruptions, or government actions. 

Severability 

Partial Invalidity: If any provision of these Terms is deemed unenforceable or invalid by a court, the remaining provisions will remain in effect to the maximum extent permissible. 

Entire Agreement 

Integration: These Terms, along with our Privacy Policy and any separate written contract for services, constitute the entire agreement between you and Newfore, superseding all prior or contemporaneous communications. 

Contact Us 

Queries: If you have any questions regarding these Terms & Conditions or our services, please contact us at: 

  • Tel: (289) 201-7888 
  • Address: 435 McNeilly Rd, Unit 104 Stoney Creek, ON L8E 5E3